REF: ELECTRICIAN-WORK-CONTRACT ELECTRICAL WORK SERVICE CONTRACT
THIS ELECTRICAL WORK CONTRACT (the "Contract") is made and executed on this [Contract Date] by and between:
ELECTRICAL CONTRACTOR / CERTIFIED ELECTRICIAN:
[Electrician / Contractor Name], holding Electrical Wireman / Contractor License No. [Wireman / Contractor License Number]
(hereinafter referred to as the "Contractor", which expression shall unless repugnant to the context include their successors, legal heirs, and permitted assigns) of the FIRST PART;
AND
CLIENT / PREMISES OCCUPIER:
[Client Full Name], occupying or owning the premises specified below
(hereinafter referred to as the "Client", which expression shall unless repugnant to the context include their successors, legal heirs, and permitted assigns) of the SECOND PART.
The Contractor and the Client are hereinafter individually referred to as a "Party" and collectively as the "Parties".
WHEREAS:
A. The Client desires to carry out electrical installation, repair, wiring, switchgear fitting, and distribution board setup at the property located at [Premises Address] (the "Premises").
B. The Contractor represents that they hold a valid electrical competency certificate / wireman license No. [Wireman / Contractor License Number] issued under the relevant State Electricity Licensing Board regulations, and possess the necessary technical expertise, insulated diagnostic tools, and equipment to perform high-grade electrical work safely and compliantly.
C. The Parties desire to record their formal agreement in writing to govern the scope, compensation, safety measures, and warranties.
NOW THIS CONTRACT WITNESSETH AND IT IS HEREBY MUTUALLY CONVENANTED AS FOLLOWS:
1. SCOPE OF ELECTRICAL WORK
1.1 The Contractor agrees to provide skilled electrical services at the Premises strictly as outlined below:
[Scope of Electrical Works]
1.2 Any additional load enhancement, circuit tracing, external high-tension pole work, or alterations ordered by the Client shall constitute extra work and shall be separately billed based on mutually agreed spot rates.
2. STATUTORY COMPLIANCE AND SAFETY REGULATIONS
2.1 The Contractor shall perform all works in strict adherence to the Indian Electricity Rules, 1956, the Central Electricity Authority (Measures relating to Safety and Electric Supply) Regulations, 2010, and the specifications set forth in:
[Safety Standards and Statutory Compliance]
2.2 The Contractor shall ensure proper chemical earthing or copper plate earthing connections are tested with a digital earth resistance tester to ensure earth resistance values comply with the Bureau of Indian Standards (BIS) norms.
2.3 The Contractor shall observe all mandatory electrical safety protocols, including de-energizing lines before commencing wiring, using insulated personal protective equipment (PPE), and installing adequate overload protection devices.
3. MATERIALS, SPECIFICATIONS, AND CONDUITS
3.1 All wires, cables, switches, sockets, conduits, miniature circuit breakers (MCBs), and residual current circuit breakers (RCCBs) used shall strictly adhere to:
[Materials and Component Specifications]
3.2 All conductors used for internal domestic or commercial wiring shall be multi-strand, high-conductivity electrolytic copper conductors with Flame Retardant Low Smoke (FRLS) insulation bearing genuine ISI certification marks.
4. CONSIDERATION AND PAYMENT SCHEDULE
4.1 The total agreed price for the completion of the electrical works detailed herein is INR [Total Contract Value (INR)] (Indian Rupees [Total Contract Value (INR)]).
4.2 All payments shall be remitted through the agreed mode of: UPI Transfer.
4.3 Unless otherwise agreed, payment shall be structured as: thirty percent (30%) advance upon mobilization; forty percent (40%) upon completion of rough-in conduit and wiring pulls; and the remaining thirty percent (30%) upon final installation of switchgear, live load testing, and circuit verification.
5. WARRANTY AND TESTING
5.1 The Contractor shall thoroughly test each circuit under load, carry out insulation resistance (megger) tests, and demonstrate faultless operation to the Client before formal handover.
5.2 The Contractor warrants all workmanship, terminations, switchboard dress-ups, and jointing against loose connections, short circuits caused by bad craftsmanship, and installation faults for a period of [Workmanship Warranty Period].
5.3 Any breakdown or short circuit occurring during the warranty period attributable directly to poor workmanship shall be rectified by the Contractor within twenty-four (24) hours of notice without additional labor charge.
6. RISK ALLOCATION AND LIMITATION OF LIABILITY
6.1 The allocation of operational risks and liabilities between the Parties is defined as follows:
[Liability and Risk Allocation Clause]
6.2 The Contractor shall not be held liable for fire, voltage fluctuations, transformer burnouts, or lightning strikes arising from the local electricity distribution company (DISCOM) grid supply, nor for appliance failures due to internal electronic component defects of devices plugged in by the Client.
7. GOVERNING LAW AND DISPUTE RESOLUTION
7.1 This Contract shall be governed by, interpreted, and enforced in accordance with the laws of India, specifically the Indian Contract Act, 1872, and the Electricity Act, 2003.
7.2 All disputes arising between the Parties in relation to this Contract shall first be attempted to be amicably settled. If unresolved within twenty-one (21) days, the matter shall be referred to arbitration under the provisions of the Arbitration and Conciliation Act, 1996, before a sole arbitrator to be appointed by mutual consent.
7.3 The courts having territorial jurisdiction over [Premises Address] shall have exclusive jurisdiction over legal proceedings connected with this Contract.
IN WITNESS WHEREOF, the Parties have executed this Electrical Work Contract on the day, month, and year first written above.
CONTRACTOR / ELECTRICIAN:
Signature: __________________________
Name: [Electrician / Contractor Name]
License No.: [Wireman / Contractor License Number]
Date: [Contract Date]
CLIENT:
Signature: __________________________
Name: [Client Full Name]
Date: [Contract Date]
WITNESS 1:
Signature: __________________________
Name: _______________________________
Address: ____________________________
WITNESS 2:
Signature: __________________________
Name: _______________________________
Address: ____________________________
SCHEDULE OF TERMS, COVENANTS & CONDITIONS(6 ACTIVE CLAUSES)
1. TENURE & TERM OF LEASE: The term of this lease/tenancy shall be for a fixed duration of {{duration_months}} months commencing on {{commencement_date}} and terminating on {{expiry_date}} unless renewed by mutual consent.
2. MONTHLY RENT & DUE DATE: The Second Party covenants to remit a monthly rent of Rs. {{monthly_rent}} payable in advance on or before the {{rent_due_day}} day of each calendar month.
3. REFUNDABLE SECURITY DEPOSIT: The Second Party has deposited an interest-free refundable security sum of Rs. {{security_deposit}} with the First Party, returnable within 7 banking days of vacant handover.
4. PERMITTED USE OF PREMISES: The demised premises shall be utilized exclusively for lawful residential dwelling purposes and shall not be converted into commercial or industrial use.
5. STATUTORY ARBITRATION (ACT 1996): Any dispute arising hereunder shall be referred to a sole arbitrator appointed mutually under the Arbitration and Conciliation Act, 1996, with seat of arbitration in the execution city.
6. SUB-LEASE & ASSIGNMENT PROHIBITION: The Second Party is strictly prohibited from sub-letting, parting with possession, or assigning any portion of the premises to third parties without prior written consent.
ATTESTATION BY INDEPENDENT WITNESSES (AS PER APPLICABLE LAW)
First Witness
Signature:
Full Name:
Parent / Spouse:
Address:
Govt ID / Aadhaar:
Second Witness
Signature:
Full Name:
Parent / Spouse:
Address:
Govt ID / Aadhaar:
